|
|
United States v. Rice, 317 U.S. 61 (1942)
Contents:
Show Summary
Hide Summary
General SummaryThis case is from a collection containing the full text of over 16,000 Supreme Court cases from 1793 to the present. The body of Supreme Court decisions are, effectively, the final interpretation of the Constitution. Only an amendment to the Constitution can permanently overturn an interpretation and this has happened only four times in American history.
United States v. Rice, 317 U.S. 61 (1942)
Please note: this case begins in mid-page. It therefore shares a citation with the last page of the previous case. If you are attempting to follow a link to the last page of 317 U.S. 56, click here.
United States v. Rice No. 31 Argued October 22, 1942 Decided November 9, 1942 317 U.S. 61
CERTIORARI TO THE COURT OF CLAIMS
Syllabus
Under a Government contract for the installation of equipment in a building, the contractor agreed to complete the work within the time allowed under another contract, with another contractor, for the construction of the building. The building contract provided for completion within 250 days after notice, but permitted changes in the specifications to be made in the event of discovery of subsurface conditions materially different from those shown in the drawings or indicated in the specifications. Shortly after notice to begin had been given, work under the building contract was suspended pending the making of such a permitted change.
Held:
1. A delay resulting from such a permitted change did not constitute a breach by the Government of the equipment contract. P. 64.
The Government was not bound to have the building ready for the work of the equipment contractor at a particular time.
2. The equipment contractor was not entitled to recover consequential damages for delay thus resulting; for such a delay, extension of the time for completion was an "equitable adjustment" under the contract. P. 66.
95 Ct.Cls. 84, reversed.
Contents:
Chicago:
U.S. Supreme Court, "Syllabus," United States v. Rice, 317 U.S. 61 (1942) in 317 U.S. 61 317 U.S. 62. Original Sources, accessed August 30, 2025, http://www.originalsources.com/Document.aspx?DocID=WMGK794FLJBNSLJ.
MLA:
U.S. Supreme Court. "Syllabus." United States v. Rice, 317 U.S. 61 (1942), in 317 U.S. 61, page 317 U.S. 62. Original Sources. 30 Aug. 2025. http://www.originalsources.com/Document.aspx?DocID=WMGK794FLJBNSLJ.
Harvard:
U.S. Supreme Court, 'Syllabus' in United States v. Rice, 317 U.S. 61 (1942). cited in 1942, 317 U.S. 61, pp.317 U.S. 62. Original Sources, retrieved 30 August 2025, from http://www.originalsources.com/Document.aspx?DocID=WMGK794FLJBNSLJ.
|